217-351-5288 800-660-7323 classifieds@news-gazette.com

Announcements

!!ATTENTION!!

!!ATTENTION!!

Were you an insulator or sheet metal worker in the Champaign IL area in the 1960's or 1970's? If so please call Dave Ruebhausen (618)910-8218.


2 burial lots in Lincoln

2 burial lots in Lincoln Cemetery. 1-$850 or both $1600. 359-4695.


ADVERTISEMENT FOR BIDS

ADVERTISEMENT FOR BIDS

1.1 PROJECT INFORMATION

A. Notice to Bidders: Qualified bidders may submit bids for project as described in this Document. Submit bids according to the Instructions to Bidders.

B. Project Identification: MTD Lift Replacement.

1. Project Location: 803 E. University Ave., Urbana, IL, 61802.

C. Owner: Champaign-Urbana Mass Transit District (MTD).

D. Architect: IGW Architecture (Isaksen Glerum Wachter LLC), 114 West Main Street, Urbana IL 61801, Telephone No. (217) 328-1391.

Project Description: The project consists of removing and disposing two (2) existing lifts at two bays of the MTD Maintenance Facility. Furnishing and installing two (2) new lifts in those two bays in the existing MTD bus maintenance facility including associated concrete and electrical work. Two additional lifts are bid as alternate bids.

E. Construction Contract: Bids will be received for the following Work:

1. General Contract (all trades).

2. Any contract resulting from these bids is subject to financial assistance contracts between CU-MTD and the United States Department of Transportation and the Illinois Department of Transportation.

3. Contractor will be required to comply with all applicable Equal Employment Opportunity laws and regulations.

4. The construction work for this project is subject to the Federal Davis-Bacon Prevailing Wage Act, in the matter of prevailing wages. As such, the general prevailing rate of wages in the locality for each craft or type of worker or mechanic needed to execute the contract or perform such work, also the general prevailing rate for legal holiday and overtime work, as ascertained by the United States Department of Labor, shall be paid for each craft or type of worker needed to execute the contract or to perform such work. Accurate payroll records shall be kept by the Contractor and each subcontractor, and shall be submitted with each pay request

5. The District also hereby notifies bidders that they affirmatively ensure that all Disadvantaged Business Enterprises, as defined by the United States Government, are afforded full opportunity to submit proposals in response to this invitation and will not knowingly discriminate against any bidder upon the grounds of gender, race, color or national origin in the consideration of award of the contract. The contractor will be required to comply with all applicable Federal and State Equal Opportunity laws and regulations. The DBE goal for this project is 5.45%. The DBE Directory can be found at the Illinois Unified Certification Program (UCP) website: http://www.idot.illinois.gov/doing-business/certifications/disadvantaged...

6. The District will be bound by the terms and conditions of the bid only to the extent funds from whatever source are available.

1.2 BID SUBMITTAL AND OPENING

A. MTD, Urbana, Illinois will receive sealed lump sum bids until the bid time and date at the location given below. Owner will consider bids prepared in compliance with the Instructions to Bidders issued by Owner, and delivered as follows:

1. Pre-Bid Date: 09 July 2019

2. Pre-Bid Time: 1:30 p.m. CST, local time.

3. Location: MTD Maintenance Facility, 803 E. University Ave., Urbana, IL, 61802.

4. Bid Date: 16 July 2019

5. Bid Time: 1:30 p.m. CST, local time.

6. Location: MTD Headquarters, 1101 E. University Ave., Urbana, IL, 61802.

B. Bids will be thereafter publicly opened and read aloud.

C. The right is reserved to accept any bid or any part or parts thereof or to reject any and all bids. The District, with concurrence of the Illinois Department of Transportation (IDOT), will award the bid to the most qualified, responsive and responsible bidder that submits the lowest priced bid based on the base bid plus any accepted alternates. After selection, the owner reserves the right to exercise the alternate. Acceptance of any bid is subject to concurrence by IDOT (and the US DOT).


1.3 BID SECURITY

A. A bid bond, bank draft, or certified check made payable to the MTD Board, Urbana, Illinois, in the amount of ten percent of the Base Bid proposal shall accompany each bid as a guarantee that the Bidder, if awarded the Contract, will furnish satisfactory Performance Bond, Labor and Material Payment Bond, in the amount of 100% of the contract sum, execute the Contract and proceed with the Work. Upon failure to do so, he/she shall forfeit the deposit or amount of bid bond as liquidated damages, and no mistakes or errors on the part of the Bidder will excuse the Bidder or entitle him/her to a return of the deposit or bid bond. No Bidder may withdraw his/her bid for a period of 120 days after the date of opening thereof. The bid bonds or checks will, with the exception of those of the three lowest bidders, be returned seven days after the opening of bids and the remaining checks or bid bonds will be returned when the Contract is executed and bond provided.

B. The successful bidders will be required to furnish a Performance Bond and Labor and Material Payment Bond in form and Surety as specified and in the full amount of the contracts. Cost of such bonds shall be included in the Bidder's Proposal.


1.4 SITE VISIT

A. Bidders are asked to contact owner to visit the site.


1.5 DOCUMENTS

A. Procurement and Contracting Documents will be available after June 17, 2019 by contacting Sharada Panditi at spanditi@igwarchitecture.com.

B. Viewing Procurement and Contracting Documents: Examine after June 17, 2019, at the locations below:

1. IGW Architecture: 114 West Main Street, Urbana, IL 61801.

2. MTD Administration Office: 1101 E. University Ave, Urbana, Illinois 61801

1.6 TIME OF COMPLETION

A. Successful bidder shall begin the Work on receipt of the Notice to Proceed and shall complete the Work within the Contract Time as stated on the Bid Proposal.


1.7 BIDDER'S QUALIFICATIONS

A. Bidders must be properly licensed under the laws governing their respective trades and be able to obtain insurance and bonds required for the Work.

B. The successful bidders will be required to furnish a Performance Bond, separate Labor and Material Payment Bond, and Insurance in form and Surety as specified and in the full amount of the contracts. Cost of such bonds shall be included in the Bidder's Proposal.


1.8 NOTIFICATION

A. This Advertisement for Bids document is issued by the Champaign-Urbana Mass Transit District.

#1410878, 6/16


Advertisement for Bids

Advertisement for Bids

City of Urbana

Department of Public Works

706 South Glover Avenue

Urbana, Illinois 61802

Sealed BIDS for the construction of the 2019 Full Asphalt Patching Project (City Section 19-00622-00-PV) including: asphalt pavement patching of 2" removal and replacement; and other incidental work will be received by the City of Urbana at the office of the City Engineer, 706 South Glover, Urbana, Illinois 61802 until 1:55 p.m. prevailing time on Thursday, June 27, 2019 and publicly opened and read aloud at 2:00 p.m. at said office.

The Bid Documents may be examined and copies obtained at the office of the City Engineer, 706 South Glover Avenue, Urbana, Illinois 61802.

All bidders are required to provide current financial and experience statements or other prequalification documents to show satisfactory evidence of the bidder's competency to perform the proposed work at the time the Contract Documents and Specifications are requested or picked up. The bidder must submit evidence of current prequalification with the Illinois Department of Transportation.

Each bid shall be accompanied by a certified check, bank draft, bank cashier's check or bid bond acceptable to the Owner in an amount not less than five percent (5%) of the amount bid, payable without condition to the Owner as a guaranty that the Bidder, if awarded the Contract, will promptly execute the Agreement in accordance with the Proposal and the other Contract Document, and will furnish good and sufficient bond for the faithful performance of the work.

As required by the Illinois Prevailing Wage Act, the general prevailing rate of wages in the locality for each craft or type of worker or mechanic needed to execute the contract or perform such work, also the general prevailing rate for legal holiday and overtime work, as ascertained by the City of Urbana, shall be paid for each craft or type of worker needed to execute the contract or to perform such work.

This contract will be awarded to the lowest responsive and responsible bidder considering conformity with the terms and conditions established by the City of Urbana in the proposal and contract documents. The City reserves the right to determine responsibility at the time of award, to reject any or all proposals, to re-advertise the proposed improvement, and to waive technicalities.

DATED this 13th day of June, 2019

Craig E. Shonkwiler, P.E.

Interim City Engineer

#1410917, 6/16


ASSUMED NAME

ASSUMED NAME

PUBLICATION NOTICE

Public notice is hereby given that on June 4, 2019, a certificate was filed in the Office of the County Clerk of Champaign County, Illinois, setting forth the names and post office addresses of all the persons owning, conducting, and transacting the business known as Bob's Woodshop located at 309 Deerfield Dr., Rantoul, IL 61866.

Aaron Ammons,

County Clerk

#1410837, 6/16,23,30


ASSUMED NAME

ASSUMED NAME

PUBLICATION NOTICE

Public notice is hereby given that on May 31, 2019 a certificate was filed in the Office of the County Clerk of Champaign County, Illinois, setting forth the names and post office addresses of all the persons owning, conducting, and transacting the business known as Heavenly Designs by Harriet Located at 1803 Winchester Dr Champaign IL 61821

Aaron Ammons,

County Clerk

1410011 6/2,9,16


ASSUMED NAME

ASSUMED NAME

PUBLICATION NOTICE

Public notice is hereby given that on May 31, 2019 a certificate was filed in the Office of the County Clerk of Champaign County, Illinois, setting forth the names and post office addresses of all the persons owning, conducting, and transacting the business known as T-Style Concepts Located at 1506 Summit Ridge Rd. Champaign IL 61821.

Aaron Ammons,

County Clerk

1410030 6/2,9,16


GREAT RETIREMENT

GREAT RETIREMENT

BUSINESS OPPORTUNITY

- Seeking Owner-Operator for

Vendor / Ad Displays in

Champaign, IL

- $10,000 to $20,000 Purchase

Prices

- Existing accounts on location

- 2 days a week Job

- $3000 a Month with incentives

Email:curtisproducts@yahoo.com to inquire for more information.


IN THE CIRCUIT COURT OF THE

IN THE CIRCUIT COURT OF THE

SIXTH JUDICIAL CIRCUIT

CHAMPAIGN COUNTY, ILLINOIS

PROBATE DIVISION

In The Matter of the Estate of: )

Myrtle Smith, ) Estate No. 19-P-161
Deceased. )

NOTICE FOR PUBLICATION - PROBATE AND CLAIMS

NOTICE IS GIVEN IN THE ESTATE OF Myrtle Smith. Letters of Independent Administration were issued to Elijah M. Smith on June 11, 2019, whose attorney is Law Offices of Mark Ingersoll, 201 W. Green St., Suite C, Urbana, IL 61801.

Claims against the Estate may be filed in the Office of the Clerk of the Circuit Court, Champaign County Courthouse, 101 E. Main St., Urbana, Illinois, 61801, within two years of Myrtle Smith's date of death on March 27, 2014, and any claim not filed within that time period is barred. Copies of a claim filed with the Clerk must be mailed or delivered to the Representative and Attorney within ten days after it has been filed.

Prepared By:

Law Offices of Mark Ingersoll

201 W. Green St., Suite C

Urbana, Illinois 61801

(217) 344-9906

#1410908, 6/16,23,30


AMENDED NOTICE

IN THE CIRCUIT COURT OF THE

SIXTH JUDICIAL CIRCUIT

CHAMPAIGN COUNTY, ILLINOIS


CITY OF CHAMPAIGN, ILLINOIS, )

a municipal corporation, )

Plaintiff, )

v. ) No. 2018-MR-762

PAMELA R. MARSHALL; MORTGAGE )

ELECTRONIC REGISTRATION SYSTEMS )

INC., AS NOMINEE FOR CTX MORTGAGE )

COMPANY, LLC; and WELLS FARGO )

BANK, N.A., )

Defendants. )


AMENDED NOTICE

The requisite affidavit for publication having been filed, notice is hereby given you, PAMELA R. MARSHALL; MORTGAGE ELECTRONIC REGISTRATION SYSTEMS INC., AS NOMINEE FOR CTX MORTGAGE COMPANY, LLC; and WELLS FARGO BANK, N.A., Defendants in the above-entitled suit, that this suit has been commenced in the Circuit Court of Champaign County by the Plaintiff against you and other Defendants regarding an unsafe structure, praying for an order of court to repair the structure by a date certain to be determined by the Court, or in the alternative, to abate the nuisance described in the Complaint by demolishing the structure by a date certain to be determined by the Court, at the expense of the Defendants, and for an order authorizing the Plaintiff to demolish the structure and to file a lien against the premises for the cost of the demolition in the event the Defendants fail to repair or demolish the structure as ordered by the Court, the premises being described as follows, to-wit:

Lot 120 in Third Plat of Garden Hills Subdivision, as per Plat recorded in Plat Book “M” at Page 32, situated in Champaign County, Illinois

(PIN: 41-20-02-308-013)

commonly known as 1507 Garden Hills Drive, Champaign, Illinois, in accordance with the provisions of the Municipal Code of Champaign, 1985, as amended, and 65 ILCS 5/11-31-11 and 11-31-2.

NOW, THEREFORE, unless you, the above-named Defendants, file your answer to the Complaint in this suit or otherwise make your appearance therein in the office of the Clerk of the Circuit Court of Champaign County, Champaign County Courthouse, Urbana, Illinois, on or before the 12th day of July 2019, default may be entered against you at any time after that day and a judgment be entered in accordance with the prayer of the Complaint.

DATED this 10th day of June 2019, at Champaign, Illinois.

Circuit Clerk

#1410678, 6/16,23,30